Housing Decoration Contract Principal (Party A):
The undertaker (Party B):
project:
After friendly negotiation and negotiation between Party A and B, Party A decided to appoint Party B to decorate the room. In order to ensure the smooth progress of the project, according to the relevant laws and regulations of the country, this contract is specially signed for mutual compliance.
Article 1: Project Overview
1. Project address: ___________________________________
2. Room specifications: Room type ______ floor (style) ______ room ______ room ______ kitchen ______ Wei, a total construction area of ​​____________ square meters.
3. Construction Content: are specified in Appendix (a) "single-family construction and decoration content" and construction.
4. Delegate method: ____________________________________________
5. Commencement Date: ______ ______ day of ______ month
6. Project completion date: ______ years ______ ______ total number of days in a month works date: ________ day of the second article: project cost project cost (the amount of capital) ___________________ yuan, specified in Appendix (II) "family decoration Engineering materials budget table. "
1, the material section __________ yuan; 2, labor costs __________ yuan;
3, the design fee __________ yuan; 4, the construction of clear freight __________ yuan;
5, unloading fee __________ yuan; 6, management fee __________ yuan;
7, other costs (marked content) ______________ yuan.
Article 3: Quality Requirements
1. The types, specifications, and names of the main materials used in the project are recognized by both parties.
2. Project acceptance standards, the two sides agreed to implement the relevant national regulations.
3. In the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and increase the additional costs and shall sign another supplementary contract.
4. Where the materials and equipment purchased by Party A itself, the quality of the product shall be borne by Party A; the construction quality shall be the responsibility of Party B.
5. If Party A hires project supervisors, Party B must notify Party B before the construction of the project to facilitate the work connection.
Article IV: Material Supply
1. Party B shall be in strict accordance with relevant national price regulations for materials used in this contract shall be clearly marked. The materials provided by Party A shall be used in the decoration works stipulated in this contract, and shall not be used for other purposes without the consent of Party A. If Party B uses it for other purposes, Party B shall compensate Party A according to the double price of the misappropriated material.
2. If the materials and equipment provided by Party B do not meet the quality requirements or the specifications are different, they should be prohibited from use. If it has been used, Party B shall be responsible for the losses caused to the project.
3. The materials and equipment that Party A is responsible for procurement and supply shall be qualified products that meet the design requirements and shall be supplied to the site on time. If the delay arrives, the construction period will be postponed and the penalty will be imposed on the delay. 10% of the total amount of materials provided by Party A shall be paid to Party B as management fees. After the materials are accepted by Party B, Party B shall be responsible for the safekeeping. If the losses are caused due to improper storage, Party B shall be responsible for compensation.
Article 5: Payment Method
1. Once the contract is signed, Party A will pay 100% of the project materials and 50% of the construction cost. When the schedule is over half (year, month, day), Party A will pay 40% of the construction fee for the second time. The remaining 10% of the balance shall be settled by Party A after acceptance of the project. (Note: Construction costs include labor costs).
Party A's failure to pay on the due date is a breach of contract. Party B has the right to stop the construction. Acceptance of the project price that is not settled may not be delivered.
2. If there is an increase or decrease of the project or needs to be changed during the construction of the project, both parties shall sign a supplementary contract and Party B shall be responsible for issuing a construction change order to inform the person in charge of the construction site. Increase or decrease the price of the project and settle it on the spot.
3. If Party A fails to pay the project price in advance according to the time limit specified in this contract, it shall pay Party B at least 1% of the unpaid project price for each overdue day.
4. If Party A mortgages the bank in the decoration of the living room, it must submit the voucher and related documents (copy) of the mortgage to Party B.
Article 6: Project Duration
1. If delays are made due to the cause of Party B, 1% per day as a penalty fine is paid to Party A, until the fees are deducted. If delays are made due to Party A's reasons, 1% of the labor cost of the decoration project shall be paid to Party B as a late work fee for each day of delay.
2. The materials and equipment selected by Party A will affect the project quality and construction period because of unqualified quality. The rework cost shall be borne by Party A. Due to the quality accident caused by Party B's construction, the rework cost shall be borne by Party B. The construction period shall not change.
3. During the construction, due to project quality problems and the disagreement between the two sides resulting in suspension of work, both parties did not follow the deadline for work delay or delay. The parties should actively request the mediation or arbitration departments of the relevant departments to coordinate and handle the disputes as soon as possible so as to continue the construction.
4. If you request re-rework due to Party A's reason during construction, or if you delay the construction period due to Party A's alteration of the construction content, you need a visa. Party A must bear all the construction costs. If Party B causes rework, Party B shall bear the responsibility. The duration will not change.
5. In the course of construction, Party A shall, without the consent of Party B, notify the construction personnel of unauthorized changes to the quality problems caused by the construction content and delay the construction period. Party A shall be responsible.
Article 7: Project Acceptance
1. Acceptance of project quality. Except for concealed projects that need to be accepted by section, Party B shall organize Party A to complete the acceptance after the completion of the project. Both parties handle project settlement and handover procedures.
2. After Party B notifies Party A of the process acceptance and completion acceptance, Party A shall come and accept the inspection within three days. If Party B lapses, it shall be deemed that Party A has waived its rights and deemed to be qualified. If there is any problem, Party A shall be responsible. Party A will move into the apartment and will be deemed as qualified.
3. Party A shall notify Party B in a timely manner if it cannot be accepted within the time limit specified by Party B. However, Party A shall acknowledge the completion date of the process or project and shall bear Party B's care fees and related expenses.
Article 8: Other matters
1. Party A's responsibilities 1) Must provide the floor plan of the house approved by the realty management department and the water, electricity and gas circuit diagrams, or Party A shall provide the house plan and the water, electricity and gas circuit diagrams, and shall submit the floor to Party B. 2) In the secondary decoration project, all houses shall be vacated or partially vacated to remove obstructions that affect the construction. For the furniture and furnishings left in houses that can only be partially vacated, the necessary protective measures must be taken. All of them must go through formalities with Party B and bear the expenses. 3) If it is really necessary to demolish or change the original building structure or equipment or pipelines, it shall go through procedures with the local housing management department and bear the relevant expenses. If you need to temporarily use common parts during construction, you should say hello to your neighbours.
2. Party B's responsibility
1) The company's business license, membership certificate, or construction qualification should be presented on its own initiative; the salesman must have an entrusted certificate of legal representative.
2) Appoint a staff member as the site representative of Party B, responsible for the performance of the contract, organize the construction according to the contract, and complete the construction task on time and in good quality.
3) Responsible for the safety of the construction site, prevent fires, certify posts, civilized construction, and prevent accidents such as pipeline blockage, leakage of water, power outage, and damage to the goods caused by construction and affect others. In case of occurrence, it must be repaired or compensated as soon as possible.
4) Strict performance of the contract, the implementation of the credit duration, if delayed due to delays in completion, such as material, work or excuse to induce Party A to make advances, the investigation will be based on breach of contract.
5) Assume the responsibility for the warranty within the range of construction work. The warranty period is 12 months from the date of acceptance of the project completion A-side inspection income.
Article 9: After the breach of contract liability contract comes into effect, during the performance of the contract, if the party terminates the contract without authorization, it shall pay the other party according to 5% of the total amount of the contract as the breach penalty. If the contract is cancelled without authorization and the actual damage caused by the other party exceeds the liquidated damages, compensation shall be made.
Article 10: Dispute Settlement During the performance of this contract, if there is a dispute between the two parties, the two parties shall negotiate a settlement without prejudice to the progress of the project. If the parties are unwilling to resolve the dispute through negotiation, or if the settlement cannot be reached through consultation, they may file a lawsuit in the People's Court in accordance with this contract.
Article 11: Changes and termination of the contract 1. After the contract has been signed and signed by both parties, both parties must strictly abide by it. If any party needs to change the content of the contract, it should sign a supplementary agreement after mutual agreement. If it is necessary to terminate the contract, the party that proposed the termination of the contract must submit it in written form. The liquidated damages shall be paid at 10% of the total price of the contract and the formalities for terminating the contract shall be handled. 2. In the construction process, either party shall terminate the contract, and must submit the contract in writing to the other party. After the two parties agree to complete the liquidation formalities, the conclusion of the termination contract agreement can be regarded as the termination of the contract.
Article XII: The Contract Takes Effect 1. This contract and the annexes of the contract are stamped by both parties and become effective after being signed. 2. The supplementary contract has the same legal effect as this contract. 3. In this contract (including the contract attachment, supplementary contract) in one copy, Party A and Party B shall hold each copy.
Party A (owner): (signature) Party B: (signature)
Address of residence: Address of company:
Postal code: Postal code:
Work unit: Legal representative:
Attorney: Attorney:
Phone: Phone:
Contracting address: Contracting date:
The undertaker (Party B):
project:
After friendly negotiation and negotiation between Party A and B, Party A decided to appoint Party B to decorate the room. In order to ensure the smooth progress of the project, according to the relevant laws and regulations of the country, this contract is specially signed for mutual compliance.
Article 1: Project Overview
1. Project address: ___________________________________
2. Room specifications: Room type ______ floor (style) ______ room ______ room ______ kitchen ______ Wei, a total construction area of ​​____________ square meters.
3. Construction Content: are specified in Appendix (a) "single-family construction and decoration content" and construction.
4. Delegate method: ____________________________________________
5. Commencement Date: ______ ______ day of ______ month
6. Project completion date: ______ years ______ ______ total number of days in a month works date: ________ day of the second article: project cost project cost (the amount of capital) ___________________ yuan, specified in Appendix (II) "family decoration Engineering materials budget table. "
1, the material section __________ yuan; 2, labor costs __________ yuan;
3, the design fee __________ yuan; 4, the construction of clear freight __________ yuan;
5, unloading fee __________ yuan; 6, management fee __________ yuan;
7, other costs (marked content) ______________ yuan.
Article 3: Quality Requirements
1. The types, specifications, and names of the main materials used in the project are recognized by both parties.
2. Project acceptance standards, the two sides agreed to implement the relevant national regulations.
3. In the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and increase the additional costs and shall sign another supplementary contract.
4. Where the materials and equipment purchased by Party A itself, the quality of the product shall be borne by Party A; the construction quality shall be the responsibility of Party B.
5. If Party A hires project supervisors, Party B must notify Party B before the construction of the project to facilitate the work connection.
Article IV: Material Supply
1. Party B shall be in strict accordance with relevant national price regulations for materials used in this contract shall be clearly marked. The materials provided by Party A shall be used in the decoration works stipulated in this contract, and shall not be used for other purposes without the consent of Party A. If Party B uses it for other purposes, Party B shall compensate Party A according to the double price of the misappropriated material.
2. If the materials and equipment provided by Party B do not meet the quality requirements or the specifications are different, they should be prohibited from use. If it has been used, Party B shall be responsible for the losses caused to the project.
3. The materials and equipment that Party A is responsible for procurement and supply shall be qualified products that meet the design requirements and shall be supplied to the site on time. If the delay arrives, the construction period will be postponed and the penalty will be imposed on the delay. 10% of the total amount of materials provided by Party A shall be paid to Party B as management fees. After the materials are accepted by Party B, Party B shall be responsible for the safekeeping. If the losses are caused due to improper storage, Party B shall be responsible for compensation.
Article 5: Payment Method
1. Once the contract is signed, Party A will pay 100% of the project materials and 50% of the construction cost. When the schedule is over half (year, month, day), Party A will pay 40% of the construction fee for the second time. The remaining 10% of the balance shall be settled by Party A after acceptance of the project. (Note: Construction costs include labor costs).
Party A's failure to pay on the due date is a breach of contract. Party B has the right to stop the construction. Acceptance of the project price that is not settled may not be delivered.
2. If there is an increase or decrease of the project or needs to be changed during the construction of the project, both parties shall sign a supplementary contract and Party B shall be responsible for issuing a construction change order to inform the person in charge of the construction site. Increase or decrease the price of the project and settle it on the spot.
3. If Party A fails to pay the project price in advance according to the time limit specified in this contract, it shall pay Party B at least 1% of the unpaid project price for each overdue day.
4. If Party A mortgages the bank in the decoration of the living room, it must submit the voucher and related documents (copy) of the mortgage to Party B.
Article 6: Project Duration
1. If delays are made due to the cause of Party B, 1% per day as a penalty fine is paid to Party A, until the fees are deducted. If delays are made due to Party A's reasons, 1% of the labor cost of the decoration project shall be paid to Party B as a late work fee for each day of delay.
2. The materials and equipment selected by Party A will affect the project quality and construction period because of unqualified quality. The rework cost shall be borne by Party A. Due to the quality accident caused by Party B's construction, the rework cost shall be borne by Party B. The construction period shall not change.
3. During the construction, due to project quality problems and the disagreement between the two sides resulting in suspension of work, both parties did not follow the deadline for work delay or delay. The parties should actively request the mediation or arbitration departments of the relevant departments to coordinate and handle the disputes as soon as possible so as to continue the construction.
4. If you request re-rework due to Party A's reason during construction, or if you delay the construction period due to Party A's alteration of the construction content, you need a visa. Party A must bear all the construction costs. If Party B causes rework, Party B shall bear the responsibility. The duration will not change.
5. In the course of construction, Party A shall, without the consent of Party B, notify the construction personnel of unauthorized changes to the quality problems caused by the construction content and delay the construction period. Party A shall be responsible.
Article 7: Project Acceptance
1. Acceptance of project quality. Except for concealed projects that need to be accepted by section, Party B shall organize Party A to complete the acceptance after the completion of the project. Both parties handle project settlement and handover procedures.
2. After Party B notifies Party A of the process acceptance and completion acceptance, Party A shall come and accept the inspection within three days. If Party B lapses, it shall be deemed that Party A has waived its rights and deemed to be qualified. If there is any problem, Party A shall be responsible. Party A will move into the apartment and will be deemed as qualified.
3. Party A shall notify Party B in a timely manner if it cannot be accepted within the time limit specified by Party B. However, Party A shall acknowledge the completion date of the process or project and shall bear Party B's care fees and related expenses.
Article 8: Other matters
1. Party A's responsibilities 1) Must provide the floor plan of the house approved by the realty management department and the water, electricity and gas circuit diagrams, or Party A shall provide the house plan and the water, electricity and gas circuit diagrams, and shall submit the floor to Party B. 2) In the secondary decoration project, all houses shall be vacated or partially vacated to remove obstructions that affect the construction. For the furniture and furnishings left in houses that can only be partially vacated, the necessary protective measures must be taken. All of them must go through formalities with Party B and bear the expenses. 3) If it is really necessary to demolish or change the original building structure or equipment or pipelines, it shall go through procedures with the local housing management department and bear the relevant expenses. If you need to temporarily use common parts during construction, you should say hello to your neighbours.
2. Party B's responsibility
1) The company's business license, membership certificate, or construction qualification should be presented on its own initiative; the salesman must have an entrusted certificate of legal representative.
2) Appoint a staff member as the site representative of Party B, responsible for the performance of the contract, organize the construction according to the contract, and complete the construction task on time and in good quality.
3) Responsible for the safety of the construction site, prevent fires, certify posts, civilized construction, and prevent accidents such as pipeline blockage, leakage of water, power outage, and damage to the goods caused by construction and affect others. In case of occurrence, it must be repaired or compensated as soon as possible.
4) Strict performance of the contract, the implementation of the credit duration, if delayed due to delays in completion, such as material, work or excuse to induce Party A to make advances, the investigation will be based on breach of contract.
5) Assume the responsibility for the warranty within the range of construction work. The warranty period is 12 months from the date of acceptance of the project completion A-side inspection income.
Article 9: After the breach of contract liability contract comes into effect, during the performance of the contract, if the party terminates the contract without authorization, it shall pay the other party according to 5% of the total amount of the contract as the breach penalty. If the contract is cancelled without authorization and the actual damage caused by the other party exceeds the liquidated damages, compensation shall be made.
Article 10: Dispute Settlement During the performance of this contract, if there is a dispute between the two parties, the two parties shall negotiate a settlement without prejudice to the progress of the project. If the parties are unwilling to resolve the dispute through negotiation, or if the settlement cannot be reached through consultation, they may file a lawsuit in the People's Court in accordance with this contract.
Article 11: Changes and termination of the contract 1. After the contract has been signed and signed by both parties, both parties must strictly abide by it. If any party needs to change the content of the contract, it should sign a supplementary agreement after mutual agreement. If it is necessary to terminate the contract, the party that proposed the termination of the contract must submit it in written form. The liquidated damages shall be paid at 10% of the total price of the contract and the formalities for terminating the contract shall be handled. 2. In the construction process, either party shall terminate the contract, and must submit the contract in writing to the other party. After the two parties agree to complete the liquidation formalities, the conclusion of the termination contract agreement can be regarded as the termination of the contract.
Article XII: The Contract Takes Effect 1. This contract and the annexes of the contract are stamped by both parties and become effective after being signed. 2. The supplementary contract has the same legal effect as this contract. 3. In this contract (including the contract attachment, supplementary contract) in one copy, Party A and Party B shall hold each copy.
Party A (owner): (signature) Party B: (signature)
Address of residence: Address of company:
Postal code: Postal code:
Work unit: Legal representative:
Attorney: Attorney:
Phone: Phone:
Contracting address: Contracting date:
Villa design entrance decoration decoration door price furniture decoration design decoration project budget table
CBN abrasive is mainly used for steel parts, such as high speed steel, die steel, 45 steel, etc., can be made into electroplating CBN, resin CBN, sintered CBN. Can be made into grinding wheel, cutting pieces, grinding head. Abrasive sharp, high temperature resistance, good thermal stability, wear resistance. The hardness of CBN is higher than that of ordinary abrasives and the ability to maintain shape is one of the main characteristics of high performance abrasives. CBN is very resistant to pressure. CBN has good thermal conductivity and can achieve cold cutting during grinding.
strong wear resistance, long life
The grinding ratio of CBN wheel can reach 3500-5500, which is 100 times higher than that of ordinary corundum wheel and 3-5 times higher than that of diamond wheel.
environmental protection, no pollution, energy saving and consumption reduction
No too much powder dust.
High work efficiency and good comprehensive economic benefits
The grinding is sharp, the grinding force is small, the dressing cycle of CBN wheel is long, the dressing amount is less, and the replacement time is long. Long service cycle, high grinding ratio, can obtain better economy, good shape retention in use, do not need to change and trim grinding wheel often, save working hours, improve working conditions, is conducive to machining operation.
Cubic boron nitride is not suitable for grinding hard metals and non-metallic materials. At high grinding temperature, CBN will react with alkaline aqueous solution. CBN grinding wheel will decompose in alkaline solution at 300℃, and can decompose in trace amount in boiling water, which will destroy the crystal shape of grinding grains. Therefore, oily coolant should be used instead of water-based coolant during grinding.
Cbn Cutting Discs,Flap Disc,Grinding Disc,Cbn Cutting Blade
Henan Jinlun Superhard Material Co., Ltd , https://www.grindingwheelsmanufacturer.com